Meet the people behind the work.

Care, effort, and teamwork in every role.

The Partners

Dr. Yusfarizal Yussoff is a fearless litigator known for his thorough approach and for handling high-profile disputes involving prominent individuals and multinational corporations, regularly appearing before Malaysia’s superior and appellate courts. A natural advocate and avid reader, he is also a published author and sought-after speaker on civil litigation and Islamic banking.

Dispute Resolutions

Professional Negligence

Construction Law and Land Disputes

Company Law & Shareholders' Disputes

Constitution Law and Cross Jurisdiction Matter (Syariah & Civil)

Defamation

White Collar Crime

Society Law

AMLA and Forfeiture of Property
Advocate & Solicitor of the High Court Malaya

Licensed Company Secretary

Council Member of Malaysian Bar Council (2019/2020); (2020/2021); (2022/2023)

Chairperson of the Malaysian Bar Council National Young Lawyers & Pupils Committee

Co-Chairperson of International Malaysian Law Conference Committee, Bar Council (2022/2023)

Co-Deputy Chairperson of the Bahasa Melayu Committee, Bar Council (2019/2020)

Committee Member of the AMLA Committee, Bar Council (2019/2020)

Secretary of AIKOL ALUMNI WING (AAW)

Members of Human Rights Cluster, Yayasan Dakwah Islamiah Malaysia (YADIM)

Chairman ADVOCS

Industrial Associate (Part-time Lecturer) IIUM & USIM

Notable cases

Lead counsel for fraud & conspiracy claim by 354 FELDA settlers against FELDA, in which case the High Court awarded RM7.8 million to Plaintiffs. The decision was upheld by the Court of Appeal and the Federal Court.
Lembaga Kemajuan Tanah Persekutuan (FELDA) & Anor v. Awang Soh Mamat & Ors [2009] 5 CLJ 1

Conducted trial against public electricity provider for negligence and familiar with technical details in electricity such as phenomena of voltage surge,power surge, severe voltage transient, transformer winding etc. The Federal Court had allowed the Plaintiffs' claims in part and the High Court, after disposal of assessment proceeding, had granted damages for a sum of RM 25 million.
Batu Kemas Sdn Bhd v. Tenaga Nasional Bhd & Anor (2015) 7 CLJ 849

Representing YB Tan Sri Tuan Guru Dato' Haji Abdul Hadi bin Awang, PAS President in a suit filed against him by Christian devotees on the alleged seditious remark on the Christian missionary pursuant to Seditious Act 1948. Amongst the issues involves is whether Malaysian Civil Court has jurisdiction to declare a person having committed sedition.
Representing Majlis Agama Islam Selangor (MAIS) in judicial review case filed by SIS Forum (Malaysia) against MAIS & 2 Ors to quash a fatwa "fahaman liberalisme & pluralisme" issued by Jawatankuasa Fatwa Negeri Selangor, involving issues of jurisdictional clash between civil court and syariah court
SIS Forum (Malaysia) & Ors v. Jawatankuasa Fatwa Negeri Selangor & Ors [2018] 6 CLJ 748
Conducted hearing for Mareva Injunction, Fortuna Injunction and Originating Summon for oil and gas contract dispute involving 2 giant companies in Malaysian oil & gas industry.
Inai Offshore & Marine Engineering Sdn Bhd v. MMHE

Conducted a full trial in a dispute between a shareholder of Singaporean's oil and gas giant on issue of share held on trust.
Emas Offshore (M) Sdn Bhd v. Suhaimi Maryani & Anor [2014] 10 CLJ 279
Conducted successful appeal in a massive construction dispute involving construction of UiTM for the sub-contractor. The High Court ruled in favour of the Main Contractor and award damages for rectification work adn damages for unlawful suspension of work. On appeal, the Court of Appeal overturned the High Court's decision, stating that the suspension of work pursuant to PAM Contract on the reason of non-certification and non-payment is valid.
Kembang Serantau Sdn Bhd v. YBKU Sdn Bhd 2019

Conducted full trials and arbitration proceedings for construction's case involving issues on PAM Contract, final account, defect liability period, wrongful termination etc
Conducted a full trial for Defendant in counter claim against renowned financial institution for negligence, conspiracy to injure & defamation. Kuala Lumpur High Court awarded RM550,000-00 for damages
Maybank Finance Berhad v. Otahulu Industries (M) Sdn Bhd & 4 ors [2008] 1 LNS 56

Conducted successful trial for a renowned singer, Dato' Syeikh in an action against Universal Music for infringement of performer's right
Syeikh Abdullah Ahmad V Universal Music (M) Sdn Bhd (2017) 8 CLJ 79

Representing National Aerospace & Defence Industries (NADI) in a civil suit against Ministry of Defense and Government of Malaysia regarding supply of Bakhtan Shikan missiles for a total claim of RM10 million

Successfully conducted appeal in Court of Appeal with regards to the setting aside of Anton Pillar Order
Representing YAB Dato' Seri Haji Muhammad Sanusi bin Md Nor, Mentri Besar Kedah in an action against YB Dato' Mahfuz bin Haji Omar for defamatory remark published by YB Mahfuz in a facebook posting regarding the issue of purchase of vehicle by Syarikat Air Darul Aman (SADA)

Defending HARAKAH in an action filed by YB Datuk Seri Mujahid bin Yusof for alleged defamatory publication regarding issue of Nur Sajat and approach taken by the then government on religious issues.

Defending HARAKAH in an action filed by YB Mohamad bin Sabu for alleged defamatory publication regarding issue of internal scuffle between him and Husam Musa

Defending Berita Nasional Malaysia (BERNAMA) in several actions for alleged defamatory publications

Defending YAB Dato' Seri Haji Muhammad Sanusi bin Md Nor, Mentri Besar Kedah in an action filed by the Prime Minister; YAB Datuk Seri Anwar Ibrahim for alleged defamatory remark regarding the reputation of YAB Datuk Seri Anwar Ibrahim and the pardon given by Yang di-Pertuan Agong XV

Representing YB Dato' Sri Haji Tuan Ibrahim Tuan Man in an action against YB Rafizi Ramli for defamatory remark published by YB Rafizi Ramli in social media and press conference regarding alleged misconduct by YB Dato' Sri Haji Tuan Ibrahim Tuan Man when acting as minister of Kementerian Air dan Alam Sekitar during the period of caretaker governement.
Conducting matters involving dispute in sport association. Representing a client in an action to review the decision of Footbal Association Malaysia in suspending the client from office
Tan Sri Annuar Musa v. FAM (2014) 2 CLJ 624

Represented a group member of SENIMAN (Association of Malaysia Artist) for a declaration that the Annual General Meeting of SENIMAN is invalid. The High Court allowed the declaration after full-blown trial
Abu Bakar bin Omar & Oth v. SENIMAN (2013) 1 LNS 1143

Publication

GACOS (Gated Community Scheme): Development In Malaysia In Light Of Amendment To Strata Act Title Act 1985 (2008) 9 CLJ

Contracting Out of Contract Act 1950 (2009) 1 CLJ

Judicial Method Of Ascertaining Nature Of Charges On Book Debts [2009] 7 CLJ xxxvi

Resolving Jurisdictional Dilemma In Recent Religious Disputes By Legal Mechanisms 2022 39 No.1 INSAF 72
Civil Litigation in Malaysia: A Practical Guide To Drafting Pleading, 2016
Civil Litigation & Injunctive Reliefs In Malaysia A practical Guide, 2023

Dr. Yusfarizal Yussoff

Litigator . Corporate Adviser . Trainer.

Aziz Mohamed does not need any introduction in banking & corporate litigation field. His vast experience in handling banking dispute ranging from simple debt recovery to complicated rehabilitation of abandoned housing project, has made him well-equipped with all relevant laws. He graduated from International Islamic University Malaysia in 2003 and was called to the Bar on 10th December 2004. With 19 years of experience, he spearheads commercial, banking and corporate litigation matters at the Firm.

Commercial & Corporate Recovery

Banking Litigation

Islamic Finance

Conveyancing
Advocate & Solicitor of the High Court Malaya

Notable cases & assignments

Conducted successful hearing for Summary Judgment at the High Court and Court of Appeal level involving Bai-Bithamin Ajil and Bai' Inah facility. The novel issue is whether the financing transaction was tainted with illegality (the sale price provided in the Asset Sale Agreement is argued to be incorrect) when there was a proviso stated the Sale Price can be amended in accordance with Base Financing Rate applicable at the time of disbursement
Bank Kerjasama Rakyat Malaysia Berhad v. Brampton Holding Sdn Bhd (2015) 4 CLJ 635
Bank Kerjasama Rakyat Malaysia Berhad v. Tenggara Muhibbah

Conducted successful trial against a developer who has abandoned its project. The issue involved is whether the developer had breached letter of undertaking issued to the Bank when the project is abandoned
Bank Kerjasama Rakyat Malaysia Berhad & Oth v. Shah Alam Utama Sdn Bhd & Anor

Well experienced in handling recovery of debt involving civil action until judgment relating to housing loan, personal loan, term loan, overdraft facility, credit card facility, hire purchase, SME facility, unit trust financing, Islamic loan facility, bridging loan etc

Well experienced in handling contested foreclosure proceedings for assigned or charged properties involving Registry Title or Land Office Title and all other contested execution proceedings
Advised Bank Islam Malaysia Berhad (BIMB) on the revision of Al-Ansar SME Financing Al-ljarah Thummah Al-Bai (AITAB) legal and security documents including the Facility Agreement, Debenture/Deed of Assignment/Sale/Contract Proceeds and Deed of Guarantee to ensure compliance with Shariah Advisory Council for Islamic Banking and Takaful Bank Negara Malaysia and Islamic Financial Services Act 2013

Restructuring financing documentation on Ijarah product (AITAB & IMBT) for Bank Islam Malaysia Berhad (BIMB) to comply with Bank Negara Malaysia (BNM) policies

Instrumental in preparing legal documentation for rehabilitated abandoned housing project such as deed of assignment between the previous developer and new developer, power of attorney, novation agreement between the previous developer and the new developer and letter of authorisation to disburse from the purchaser to the end financier

Advised and lead the drafting team on preparing the Rent To Own (RTO) scheme for Perbadanan Usahawan Nasional Berhad (PUNB)
Drafting Share Sale Agreement (SSA) and Shareholder Agreement for transfer of shares involving oil & gas companies and public listed companies

Advised Permodalan Usahawan Nasional Berhad (PUNB) on the issuance of micro loans to SME under the Tawarruq Facility (Non-Revolving/Revolving Option) including drafting and finalising the facility agreement, Debenture, Deed of Assignment, Murabahah Contract and Deed of Guarantee

Handling all sorts of conveyancing & corporate documentations ranging from sale & purchase agreement, perfection of transfer and charge, to complicated share sale agreement and due diligence exercise

Talk & Training

Speaker, "Bankruptcy Proceeding"
organised by Bank Kerjasama Rakyat Malaysia Berhad (BKRM)

Speaker, "Training on Credit & Loan Processing Legal Mechanics"
organised by Bank Kerjasama Rakyat Malaysia Berhad (BKRM)

Speaker, "Civil & Foreclosure Proceeding"
organised by Bank Simpanan Nasional (BSN)

Speaker, "Hire Purchase: Procedures & Legal Consequences"
organised by Angkatan Koperasi Kebangsaan Malaysia Berhad

Speaker, "Legal Issues & Legal Documentations for Service Agreement"
organised by Bank Kerjasama Rakyat Malaysia Berhad (BKRM)

Speaker, "Recovery & Execution of Judgment"
organised by Bank Kerjasama Rakyat Malaysia Berhad (BKRM)

Speaker, "Latihan Amalan Hartanah"
organised by Bank Kerjasama Rakyat Malaysia Berhad (BKRM)

Speaker, "Legal Framework for Debt Recovery"
organised by Bank Kerjasama Rakyat Malaysia Berhad (BKRM)

Aziz Mohamed

Litigator . Corporate Adviser . Trainer.

Zaid Daud graduated from the International Islamic University Malaysia in 2006 and was called to the Bar in 2007, beginning his career under the mentorship of Yusfarizal and focusing on general litigation, particularly high-value corporate disputes. A founding partner of YAZ, he later earned his LL.M with distinction from Universiti Malaya while in practice, and now leads litigation matters involving contested corporate disputes, construction law, and tortious liability.

Dispute Resolutions

Professional Negligence

Construction Law and Land Disputes

Company Law & Shareholders' Disputes

Constitution Law and Cross Jurisdiction Matter (Syariah & Civil)

Defamation

White Collar Crime

Society Law

AMLA and Forfeiture of Property
Advocate & Solicitor of the High Court Malaya

Licensed Company Secretary

Council Member of Malaysian Bar Council (2019/2020); (2020/2021); (2022/2023)

Chairperson of the Malaysian Bar Council National Young Lawyers & Pupils Committee

Co-Chairperson of International Malaysian Law Conference Committee, Bar Council (2022/2023)

Co-Deputy Chairperson of the Bahasa Melayu Committee, Bar Council (2019/2020)

Committee Member of the AMLA Committee, Bar Council (2019/2020)

Secretary of AIKOL ALUMNI WING (AAW)

Members of Human Rights Cluster, Yayasan Dakwah Islamiah Malaysia (YADIM)

Chairman ADVOCS

Industrial Associate (Part-time Lecturer) IIUM & USIM

Notable cases

Lead counsel for fraud & conspiracy claim by 354 FELDA settlers against FELDA, in which case the High Court awarded RM7.8 million to Plaintiffs. The decision was upheld by the Court of Appeal and the Federal Court.
Lembaga Kemajuan Tanah Persekutuan (FELDA) & Anor v. Awang Soh Mamat & Ors [2009] 5 CLJ 1
Conducted trial against public electricity provider for negligence and familiar with technical details in electricity such as phenomena of voltage surge,power surge, severe voltage transient, transformer winding etc. The Federal Court had allowed the Plaintiffs' claims in part and the High Court, after disposal of assessment proceeding, had granted damages for a sum of RM 25 million.
Batu Kemas Sdn Bhd v. Tenaga Nasional Bhd & Anor (2015) 7 CLJ 849
Representing YB Tan Sri Tuan Guru Dato' Haji Abdul Hadi bin Awang, PAS President in a suit filed against him by Christian devotees on the alleged seditious remark on the Christian missionary pursuant to Seditious Act 1948. Amongst the issues involves is whether Malaysian Civil Court has jurisdiction to declare a person having committed sedition.
Representing Majlis Agama Islam Selangor (MAIS) in judicial review case filed by SIS Forum (Malaysia) against MAIS & 2 Ors to quash a fatwa "fahaman liberalisme & pluralisme" issued by Jawatankuasa Fatwa Negeri Selangor, involving issues of jurisdictional clash between civil court and syariah court
SIS Forum (Malaysia) & Ors v. Jawatankuasa Fatwa Negeri Selangor & Ors [2018] 6 CLJ 748
Conducted hearing for Mareva Injunction, Fortuna Injunction and Originating Summon for oil and gas contract dispute involving 2 giant companies in Malaysian oil & gas industry.
Inai Offshore & Marine Engineering Sdn Bhd v. MMHE

Conducted a full trial in a dispute between a shareholder of Singaporean's oil and gas giant on issue of share held on trust.
Emas Offshore (M) Sdn Bhd v. Suhaimi Maryani & Anor [2014] 10 CLJ 279
Conducted successful appeal in a massive construction dispute involving construction of UiTM for the sub-contractor. The High Court ruled in favour of the Main Contractor and award damages for rectification work adn damages for unlawful suspension of work. On appeal, the Court of Appeal overturned the High Court's decision, stating that the suspension of work pursuant to PAM Contract on the reason of non-certification and non-payment is valid.
Kembang Serantau Sdn Bhd v. YBKU Sdn Bhd 2019

Conducted full trials and arbitration proceedings for construction's case involving issues on PAM Contract, final account, defect liability period, wrongful termination etc
Conducted a full trial for Defendant in counter claim against renowned financial institution for negligence, conspiracy to injure & defamation. Kuala Lumpur High Court awarded RM550,000-00 for damages
Maybank Finance Berhad v. Otahulu Industries (M) Sdn Bhd & 4 ors [2008] 1 LNS 56

Conducted successful trial for a renowned singer, Dato' Syeikh in an action against Universal Music for infringement of performer's right
Syeikh Abdullah Ahmad V Universal Music (M) Sdn Bhd (2017) 8 CLJ 79

Representing National Aerospace & Defence Industries (NADI) in a civil suit against Ministry of Defense and Government of Malaysia regarding supply of Bakhtan Shikan missiles for a total claim of RM10 million

Successfully conducted appeal in Court of Appeal with regards to the setting aside of Anton Pillar Order
Representing YAB Dato' Seri Haji Muhammad Sanusi bin Md Nor, Mentri Besar Kedah in an action against YB Dato' Mahfuz bin Haji Omar for defamatory remark published by YB Mahfuz in a facebook posting regarding the issue of purchase of vehicle by Syarikat Air Darul Aman (SADA)

Defending HARAKAH in an action filed by YB Datuk Seri Mujahid bin Yusof for alleged defamatory publication regarding issue of Nur Sajat and approach taken by the then government on religious issues.

Defending HARAKAH in an action filed by YB Mohamad bin Sabu for alleged defamatory publication regarding issue of internal scuffle between him and Husam Musa

Defending Berita Nasional Malaysia (BERNAMA) in several actions for alleged defamatory publications

Defending YAB Dato' Seri Haji Muhammad Sanusi bin Md Nor, Mentri Besar Kedah in an action filed by the Prime Minister; YAB Datuk Seri Anwar Ibrahim for alleged defamatory remark regarding the reputation of YAB Datuk Seri Anwar Ibrahim and the pardon given by Yang di-Pertuan Agong XV

Representing YB Dato' Sri Haji Tuan Ibrahim Tuan Man in an action against YB Rafizi Ramli for defamatory remark published by YB Rafizi Ramli in social media and press conference regarding alleged misconduct by YB Dato' Sri Haji Tuan Ibrahim Tuan Man when acting as minister of Kementerian Air dan Alam Sekitar during the period of caretaker governement.
Conducting matters involving dispute in sport association. Representing a client in an action to review the decision of Footbal Association Malaysia in suspending the client from office
Tan Sri Annuar Musa v. FAM (2014) 2 CLJ 624

Represented a group member of SENIMAN (Association of Malaysia Artist) for a declaration that the Annual General Meeting of SENIMAN is invalid. The High Court allowed the declaration after full-blown trial
Abu Bakar bin Omar & Oth v. SENIMAN (2013) 1 LNS 1143

Publication

GACOS (Gated Community Scheme): Development In Malaysia In Light Of Amendment To Strata Act Title Act 1985 (2008) 9 CLJ

Contracting Out of Contract Act 1950 (2009) 1 CLJ

Judicial Method Of Ascertaining Nature Of Charges On Book Debts [2009] 7 CLJ xxxvi

Resolving Jurisdictional Dilemma In Recent Religious Disputes By Legal Mechanisms 2022 39 No.1 INSAF 72
Civil Litigation in Malaysia: A Practical Guide To Drafting Pleading, 2016
Civil Litigation & Injunctive Reliefs In Malaysia A practical Guide, 2023

Mohamad Zaid Daud

Litigator . Corporate Adviser .

WhatsApp Image 2026-04-26 at 4.48_edited.png

Muhd Daniel Baharudin

Litigator . Corporate Adviser . Marketeer.

Daniel graduated from the Royal Military College and Universiti Kebangsaan Malaysia (UKM), was called to the Bar on 6 May 2015, and has since developed a diverse litigation practice spanning aviation, criminal and corporate disputes, personal injury, land matters, industrial relations, and probate administration. He holds an LLM and a Postgraduate Advanced Diploma in Shariah Law (DSLA) from UiTM, is a licensed Company Secretary, and is known for crafting persuasive legal strategies that have secured favourable outcomes in complex cases.

Aviation

Corporate Litigation

Land Disputes

Industrial Relation Matters

Probate Administration

Personal Injury
Advocate & Solicitor of the High Court Malaya

Company Secretary

Notable cases

Representing clients in various contentious matters involving ownership, assignment of copyright and infringement

Advisory works on proposals & mediations
Facilitate the procedures in obtaining administration in respect of small estates and distributions of assets to beneficiaries

Representing clients in contested wills and probates
Advisory works on employee terminations and related disputes

Drafting employment contracts and policies

Advisory works on Dismissal/ Constructive Dismissal/Proposal & Negotiations/ Disciplinary Proceedings involving misconduct and poor performance
Recovery of debts involving civil actions until judgment and execution proceedings Drafting agreements involving vendors and suppliers

Represents Malaysia Airlines Berhad (MAB) on the proposed debt restructuring by AirAsia X
Representing client in legal action against the State Government of Johor and respective Land Office in mismanagement of land ownership and administration of estate

Representing client in dispute regarding sale and purchase agreement and transfer of ownership of respective land to the purchaser after the death of the vendor without perfection of transfer
Representing client on the proposed acquisition of entire paid up shares of property holding company

Representing client in its application of licence by Bank Negara Malaysia (BNM) to operate e-wallet and payment system operator
Conducting matters involving the Security Offences (Special Measures) Act 2012 (SOSMA)

PP v. Wan Mohamad Nur Firdaus Ab Wahab & Anor [2018] 1 LNS

Representing client on intellectual property dispute on the ownership of creative design against Polis DiRaja Malaysia (PDRM)

Representing client and successful in acquitting the accused from all charges under Section 14 of the Sexual Offences Act 2017

Munzeer graduated from the International Islamic University Malaysia (IIUM) in 2007 and was selected for Bank Negara Malaysia’s inaugural Financial Sector Talent Enrichment Programme (FSTEP), where he completed a six-month attachment with RHB Investment’s Corporate Finance Department before being offered a role in Islamic Investment and Corporate Banking at RHB Islamic.In 2010, he returned to legal practice as a pupil at Messrs Zulpadli & Edham under Yusfarizal Bin Yussoff, later specialising in general litigation and major banking disputes—including matters before the Federal Court—before joining YAZ in September 2018.

Dispute Resolutions

Construction Dispute

Banking Litigation

Medical Negligence

General Commercial Work

Shareholder Disputes
Advocate & Solicitor of the High Court Malaya

Notable cases

Lead counsel for fraud & conspiracy claim by 354 FELDA settlers against FELDA, in which case the High Court awarded RM7.8 million to Plaintiffs. The decision was upheld by the Court of Appeal and the Federal Court.
Lembaga Kemajuan Tanah Persekutuan (FELDA) & Anor v. Awang Soh Mamat & Ors [2009] 5 CLJ 1
Conducted trial against public electricity provider for negligence and familiar with technical details in electricity such as phenomena of voltage surge,power surge, severe voltage transient, transformer winding etc. The Federal Court had allowed the Plaintiffs' claims in part and the High Court, after disposal of assessment proceeding, had granted damages for a sum of RM 25 million.
Batu Kemas Sdn Bhd v. Tenaga Nasional Bhd & Anor (2015) 7 CLJ 849
Representing YB Tan Sri Tuan Guru Dato' Haji Abdul Hadi bin Awang, PAS President in a suit filed against him by Christian devotees on the alleged seditious remark on the Christian missionary pursuant to Seditious Act 1948. Amongst the issues involves is whether Malaysian Civil Court has jurisdiction to declare a person having committed sedition.
Representing Majlis Agama Islam Selangor (MAIS) in judicial review case filed by SIS Forum (Malaysia) against MAIS & 2 Ors to quash a fatwa "fahaman liberalisme & pluralisme" issued by Jawatankuasa Fatwa Negeri Selangor, involving issues of jurisdictional clash between civil court and syariah court
SIS Forum (Malaysia) & Ors v. Jawatankuasa Fatwa Negeri Selangor & Ors [2018] 6 CLJ 748
Conducted hearing for Mareva Injunction, Fortuna Injunction and Originating Summon for oil and gas contract dispute involving 2 giant companies in Malaysian oil & gas industry.
Inai Offshore & Marine Engineering Sdn Bhd v. MMHE

Conducted a full trial in a dispute between a shareholder of Singaporean's oil and gas giant on issue of share held on trust.
Emas Offshore (M) Sdn Bhd v. Suhaimi Maryani & Anor [2014] 10 CLJ 279
Conducted successful appeal in a massive construction dispute involving construction of UiTM for the sub-contractor. The High Court ruled in favour of the Main Contractor and award damages for rectification work adn damages for unlawful suspension of work. On appeal, the Court of Appeal overturned the High Court's decision, stating that the suspension of work pursuant to PAM Contract on the reason of non-certification and non-payment is valid.
Kembang Serantau Sdn Bhd v. YBKU Sdn Bhd 2019

Conducted full trials and arbitration proceedings for construction's case involving issues on PAM Contract, final account, defect liability period, wrongful termination etc
Conducted a full trial for Defendant in counter claim against renowned financial institution for negligence, conspiracy to injure & defamation. Kuala Lumpur High Court awarded RM550,000-00 for damages
Maybank Finance Berhad v. Otahulu Industries (M) Sdn Bhd & 4 ors [2008] 1 LNS 56

Conducted successful trial for a renowned singer, Dato' Syeikh in an action against Universal Music for infringement of performer's right
Syeikh Abdullah Ahmad V Universal Music (M) Sdn Bhd (2017) 8 CLJ 79

Representing National Aerospace & Defence Industries (NADI) in a civil suit against Ministry of Defense and Government of Malaysia regarding supply of Bakhtan Shikan missiles for a total claim of RM10 million

Successfully conducted appeal in Court of Appeal with regards to the setting aside of Anton Pillar Order
Representing YAB Dato' Seri Haji Muhammad Sanusi bin Md Nor, Mentri Besar Kedah in an action against YB Dato' Mahfuz bin Haji Omar for defamatory remark published by YB Mahfuz in a facebook posting regarding the issue of purchase of vehicle by Syarikat Air Darul Aman (SADA)

Defending HARAKAH in an action filed by YB Datuk Seri Mujahid bin Yusof for alleged defamatory publication regarding issue of Nur Sajat and approach taken by the then government on religious issues.

Defending HARAKAH in an action filed by YB Mohamad bin Sabu for alleged defamatory publication regarding issue of internal scuffle between him and Husam Musa

Defending Berita Nasional Malaysia (BERNAMA) in several actions for alleged defamatory publications

Defending YAB Dato' Seri Haji Muhammad Sanusi bin Md Nor, Mentri Besar Kedah in an action filed by the Prime Minister; YAB Datuk Seri Anwar Ibrahim for alleged defamatory remark regarding the reputation of YAB Datuk Seri Anwar Ibrahim and the pardon given by Yang di-Pertuan Agong XV

Representing YB Dato' Sri Haji Tuan Ibrahim Tuan Man in an action against YB Rafizi Ramli for defamatory remark published by YB Rafizi Ramli in social media and press conference regarding alleged misconduct by YB Dato' Sri Haji Tuan Ibrahim Tuan Man when acting as minister of Kementerian Air dan Alam Sekitar during the period of caretaker governement.
Conducting matters involving dispute in sport association. Representing a client in an action to review the decision of Footbal Association Malaysia in suspending the client from office
Tan Sri Annuar Musa v. FAM (2014) 2 CLJ 624

Represented a group member of SENIMAN (Association of Malaysia Artist) for a declaration that the Annual General Meeting of SENIMAN is invalid. The High Court allowed the declaration after full-blown trial
Abu Bakar bin Omar & Oth v. SENIMAN (2013) 1 LNS 1143

Mohd Munzeer Zainul Abidin

Litigator . Problem Solver .

An alumnus of Sekolah Alam Shah and IIUM, Adam Luqman Amdan was admitted to the Malaysian Bar in July 2017 after completing his pupillage under Yusfarizal Yussoff. He specializes in complex general litigation, with extensive experience handling high-stakes tortious and contractual claims involving both public and private entities. His current practice focuses on public interest litigation, shareholder disputes, and appellate advocacy. An active contributor to the legal profession, Adam frequently serves as a speaker and trainer and is a dedicated member of the Malaysian Bar Council’s National Young Lawyers and Pupils Committee.

Dispute Resolutions

Land & Construction Dispute

Shareholder Dispute

Tortious Claim

Public Interest Litigation

General Commercial Work
Advocate & Solicitor of the High Court Malaya

Member of Malaysian Bar Council National Young Lawyers & Pupils Committee (19/20)

Member of Malaysian Bar Council National Young Lawyers & Pupils Committee (20/21)

Member of Malaysian Bar Council National Young Lawyers & Pupils Committee (21/22)

Notable cases

Lead counsel for Majlis Amanah Rakyat (MARA) in a USD 3.9 million High Court dispute involving a Total Campus Management System (TCMS) agreement. The matter addressed critical issues of public-sector accountability, project non-performance, and contractual risk allocation following the termination of the project.

He successfully defended MARA’s right to call a USD 197,998 performance bond by defeating an injunction application. Adam’s strategic arguments on the autonomy principle and the absence of unconscionability ensured the High Court upheld the statutory body's financial and enforcement rights, reinforcing the principle that judgments should not be lightly stayed when public funds are at stake.
Majlis Amanah Rakyat v. Pernec Integrated Network Systems Sdn Bhd [2025] MLJU 724
High-Value Defense: Adam acted as co-counsel for a defendant in a RM 1.5 billion High Court suit initiated by FELDA and FIC against its former board of directors and several legal firms.

Complex Multi-Party Litigation: The dispute involves allegations of negligence and the tort of conspiracy regarding the multi-million ringgit KLVC Project development at Jalan Semarak, involving over 20,000 acres of prime land.

Federal Land Development Authority & Felda Investment Corporation Sdn Bhd V. Tan Sri Haji Mohd Isa Bin Dato’ Haji Abdul Samad & 20 Ors
Adam led a USD 38 million oil and gas dispute, successfully securing a USD 3.3 million damages award. He managed the case from the assessment of damages through to the final enforcement phase.
Tresenergy Sdn Bhd v. Mohd Fauzi Ya'akob & MTCE Engineering Sdn Bhd [2025] MLRHU 2088
Adam acted as co-counsel for Bank Rakyat in High Court proceedings, successfully defending the bank's foreclosure actions against a borrower's attempt to convert the matter into a lengthy writ action.

Procedural Strategy: He played a key role in formulating the strategy to dismiss the borrower’s tactical delays, reinforcing the efficiency of specialized enforcement mechanisms and protecting the bank's contractual recovery rights from abuse of process.

Bank Kerjasama Rakyat Malaysia Berhad v. Top Trident Traders Sdn Bhd & Anor
High-Stakes Director Liability: Adam acted as co-counsel for a defendant in a major High Court action filed by FGV Holdings Berhad against its former board of directors and legal firms, involving a claim of RM 514 million.

Complex Share Acquisition Dispute: The litigation centered on alleged negligence and breaches of fiduciary duty related to the 2014 acquisition of a 100% equity stake in Asian Plantation Ltd (APL). The matter required addressing technically demanding issues of reasonable care, skill, and diligence within a complex corporate share acquisition framework.

FGV Holdings Berhad v. Mohd Emir Mavani Bin Abdullah & 13 Ors
Successful Prosecution: Adam acted as co-counsel for the Menteri Besar of Kedah, YAB Dato’ Seri Haji Muhammad Sanusi bin Md Nor in a High Court defamation suit against Dato’ Mahfuz bin Haji Omar. The case centered on allegations regarding the management of Syarikat Air Darul Aman (SADA) and the water crisis in Kedah.

Judgment & Relief: He successfully proved the defamatory nature of the statements, securing a favorable judgment that included orders for damages and a permanent injunction against the defendant. The victory reinforced legal protections for public officials against unsubstantiated claims involving government-linked entities.

Tuan Haji Muhammad Sanusi Md Nor lwn Dato Mahfuz Haji Omar [2025] MLRHU 2929

Adam Luqman Amdan

Litigator . Technologist .

The Associates

Few lawyers walk into the legal profession carrying the weight of over four decades of distinguished public service. Datuk Wira Hj. Hamza bin Taib is one of them. Before joining the Firm, Datuk Wira built an illustrious career with the Royal Malaysian Police, rising from Investigation Officer in 1976 all the way to Commissioner of Police. He served as Federal Traffic Chief, Deputy Commissioner for Sarawak, and Commissioner of Police for Sabah, where he was at the helm during the historic Lahad Datu incident in 2014. He retired in 2017 as Deputy Director of Commercial Crime Investigation. A graduate of the International Islamic University of Malaysia (IIUM) in 1998 and holder of a Diploma in Shariah Legal Practice (2007), Datuk Wira now channels that formidable experience as a Senior Associate at the Firm, bringing unparalleled insight in corporate and commercial matters, criminal law, and dispute resolutions.

Corporate & Commercial

Criminal Law

Dispute Resolutions
Advocate & Solicitor of the High Court of Malaya

Commissioner of Police with the Royal Malaysian Police

Deputy Director of Commercial Crime Investigation

Datuk Wira Hj. Hamza

Litigator . Corporate Adviser .

Nabilah

Litigator . Deal Breaker .

Nabilah graduated from Universiti Teknologi MARA (UiTM) Shah Alam with a Bachelor of Laws and was called to the Bar on 16th January 2015, having chambered at Messrs Bhadarul Baharain & Partners. What followed was a career built on curiosity and range, starting at Zailan & Associates before moving to Natasha & Co, she immersed herself across tax disputes, civil and criminal matters, employment law, medical negligence and construction disputes, each chapter adding a new dimension to her practice. By the time she joined YAZ in July 2022, Nabilah had cultivated something that sets her apart. A quiet composure in the midst of complexity, and the determination to see every matter through to its resolution.

Dispute Resolutions

Construction Dispute

Medical Negligence

Tax Dispute

Employment & Industrial Dispute

Running Down
Advocate & Solicitor of the High Court Malaya

Notable cases

Nabilah represented the federal regulatory authority, SPAN, in a high-stakes dispute involving a developer's non-payment of the Sewerage Capital Contribution Fund under the Water Services Industry Act 2006. She successfully defended SPAN at every stage, securing a Judgment in Default at the Sessions Court, defeating the Appellant's attempt to set it aside, and further prevailing at the High Court on appeal. The matter now proceeds to the Court of Appeal, where SPAN's position remains firmly defended.
Nova Mulia Development Sdn. Bhd v. Suruhanjaya Perkhidmatan Air Negara (SPAN) PA-12BNCvC-3-03/202
Nabilah acted for MARA, one of Malaysia's foremost public institutions, in a breach of contract claim arising from a borrower's failure to honour obligations under a Facility Agreement valued at over RM3.4 million. Despite the Defendant's attempt to invoke res judicata as a shield, Nabilah successfully argued the merits of the claim and secured full judgment in MARA's favour.
Majlis Amanah Rakyat (MARA) v. Shabri Bin Sulong WA-22M-131-02/2024

Lya graduated with an LL.B (Hons) from the International Islamic University Malaysia (IIUM) in 2013 and was admitted to the Malaysian Bar in 2014. After a pupillage focused on personal injury claims, she specialized in conveyancing as a Legal Assistant before becoming a Partner at Norliza & Associates in 2015, where she managed civil litigation and real estate matters. In 2019, she expanded her expertise into high-level real estate, property financing, and corporate documentation at Abdul Malik & Lawrence Tan. Lya currently serves in the Firm’s Corporate & Conveyancing Department, leveraging her extensive background in transactional law and corporate agreements.

Conveyancing

Corporate Financing Transaction

Corporate Agreement Documentation
Advocate & Solicitor of the High Court of Malaya

Volunteer Solicitor at YBGK

Registered Real Estate Negotiator (REN 59897)

Lya Darwinna

Litigator . Social Media Influencer .

Ali graduated with an LL.B (Hons) from Multimedia University (MMU) in 2010 and completed his pupillage at Messrs. Suhaimi Khor Zulkifli & Chang before being called to the Bar in July 2011. He spent 11 years at Messrs. Lua & Mansor, primarily managing a banking litigation portfolio that included contested cases from trial through to the Appellate Courts, alongside general matters like land, tenancy, and shareholder disputes. In January 2022, he joined Messrs. Lee & Lim to focus on land and directors' disputes, before ultimately joining the Firm in November 2022 to continue his passion for litigation.

Banking Litigation

Land Matter

General Litigation

Debt Recovery

Shareholders & Directors Dispute

Judicial Review
Advocate & Solicitor of the High Court Malaya

Notable cases

High-Value Recovery: Acted for Export-Import Bank of Malaysia Berhad (EXIM Bank) in a full High Court trial to recover USD 3.59 million under an Islamic Financing Facility Agreement.

Judgment on Liability: Successfully navigated complex defenses concerning alleged moratoriums and challenges to the reasonableness of ta'widh (penalty charges). Ali effectively proved the bank's claim on the balance of probabilities, resulting in a successful judgment for the full outstanding sum and costs.

Export-Import Bank Of Malaysia Berhad v. Impiana Seminyak (Labuan) Co Ltd [2025] MLRHU 183
Defense of High-Value Claim: Acted for Bank Kerjasama Rakyat Malaysia Berhad (Bank Rakyat) in a full High Court trial against a RM 4 million claim brought by the Estate of a deceased investor concerning 22-year-old Al-Mudharabah Investment Certificates.

Successful Dismissal: Effectively defended the bank’s position by demonstrating that the funds had been previously withdrawn, leading to a complete dismissal of the Plaintiff’s claim with costs. This case highlights Ali's expertise in managing complex, historical banking records and successfully litigating legacy investment disputes.

Nik Anira Mohd Zain & Ors v. Bank Kerjasama Rakyat Malaysia Berhad [2025] CLJU 2417

Ali

Litigator . Social Media Influencer.

Syafiq

Litigator . Quran Reciter .

Syafiq graduated from the International Islamic University of Malaysia (IIUM) with a dual degree in Civil and Syariah Law in 2020, a combination that gave him a uniquely well-rounded legal foundation. He completed his pupillage under the guidance of Mohammad Zaid bin Daud and was called to the Bar on 4th March 2022. Throughout his pupillage, Syafiq was immersed in banking litigation disputes and commercial matters, laying the groundwork for the practice he continues to build today. He has since remained at the Firm, steadily deepening his expertise across banking litigation, commercial matters and execution proceedings. A quiet but formidable presence in everything he takes on.

Banking Litigation

Commercial Litigation

Debt Recovery

Execution Proceedings
Advocate & Solicitor of the High Court Malaya

Notable cases

Counsel for Bank Kerjasama Rakyat Malaysia Berhad in successfully defending a claim over six Al-Mudharabah Investment Certificates, amounting to RM4 million plus profits, that surfaced 22 years after issuance. Following an 11-day trial involving 15 witnesses, the High Court dismissed the claim with costs, holding that the lengthy delay raised a presumption of payment and that the claim was in any event time-barred and defeated by laches.
Nik Anira bt Mohd Zain (Sebagai pentadbir kepada pusaka Nik Mohd Zain bin Haji Omar) v Bank Kerjasama Rakyat Malaysia Bhd [2025] MLJU 2976, High Court (Kuala Lumpur)

Counsel for Bank Kerjasama Rakyat Malaysia Berhad in obtaining summary judgment for RM35,784,248.22 under a Term Financing-i facility, together with ta'widh (late payment compensation) and costs. The High Court granted judgment on the plaintiff's O.14 application following oral argument.
Bank Kerjasama Rakyat Malaysia Berhad v Muhammad Ikmal Opat bin Abdullah [Guaman No WA-22M-1902-10/2025], High Court (Kuala Lumpur), 3 April 2026

Counsel for Bank Kerjasama Rakyat Malaysia Berhad on its Order 14 application for summary judgment to recover RM2,372,677.44 outstanding under a financing facility, together with ta'widh (late payment compensation) and costs.
Bank Kerjasama Rakyat Malaysia Berhad v Koperasi Pegawai-Pegawai MARDI Berhad [Guaman No WA-22M-120-02/2020], High Court (Kuala Lumpur)
Counsel for Bank Kerjasama Rakyat Malaysia Berhad in a successful appeal against a private liquidator's proof-of-debt decision. The High Court varied the liquidator's determination, admitting the Bank's proof of debt at RM15,375,041.33, the claim net of the charged property value of RM6,383,000 — while the Bank retained the charged land.

In re MME Realty & Management Sdn Bhd (In Liquidation) [Post-Winding-Up Case No WA-28PW-497-10/2022], High Court (Kuala Lumpur), 7 December 2023
Acted for Bank Kerjasama Rakyat Malaysia Berhad, as chargee, in an order for sale enforcement, including obtaining a variation of the auction reserve price to RM8,027,383.50.
Bank Kerjasama Rakyat Malaysia Berhad v Kubang Pasu Hotel Services Sdn Bhd [Saman Pemula No KA-24MFC-195-06/2018; Perlaksanaan No KA-38-187-08/2023], High Court (Alor Setar), 19 December 2023

Amrah

Litigator . Spellbinder .

Amrah graduated from the International Islamic University of Malaysia (IIUM) in 2022 and completed her pupillage at the Firm under the guidance of Yusfarizal Yussoff. She was called to the Bar on 28th July 2023. From the very beginning, Amrah immersed herself in the full breadth of legal practice, from drafting cause papers and attending court to engaging with clients across both contentious and non-contentious matters. It was during this time that she developed a particular grounding in civil litigation and execution proceedings. Quietly diligent and thorough in her approach, Amrah continues to grow her practice at YAZ within the Litigation Department, focusing on debt recovery and contractual claims.

Debt Recovery

Contractual Claims
Advocate & Solicitor of the High Court Malaya

Notable cases

Amrah acted as lead counsel for Malaysia Airlines Berhad in a significant commercial dispute arising from the management of flight ticket deposits for religious travel seasons (2018/2019 and 2019/2020). The litigation involved defending MAB against claims of alleged non-refunds and breaches of contract related to Umrah and Hajj travel arrangements. Through strategic litigation management, Amrah addressed the complex interplay between airline refund policies and the specific regulatory requirements governing pilgrimage travel, ultimately protecting the carrier’s interests against claims totaling substantial financial and reputational stakes.

Eco Riths Leisure Travel & Tours Sdn Bhd V Malaysia Airlines Berhad (Mab)
Represented the Selangor State Development Corporation (PKNS) in a specialized application under Section 417 of the National Land Code. Amrah sought the judicial rectification of land registers to ensure the accurate reflection of proprietors and chargees for a major housing development project. This matter involved navigating complex administrative procedures and land law technicalities to safeguard the integrity of titles and the interests of stakeholders within the development.

Perbadanan Kemajuan Negeri Selangor (Pkns) V Pentadbir Tanah Hulu Langat

Mujahid

Litigator . Workaholic .

A graduate of Universiti Teknologi MARA (UiTM) in 2022, Mujahid was admitted as an Advocate and Solicitor of the High Court of Malaya in 2023 following his pupillage at the Firm under Muhd Daniel bin Baharudin. His legal practice is informed by a distinguished background as a competitive debater and adjudicator, having represented UiTM in Malaysia, Indonesia, and Vietnam, including the 2019 Debathon Parlimen Belia. Mujahid applies this analytical rigour to a diverse portfolio at YAZ, encompassing debt recovery, contractual disputes, tortious claims, judicial reviews, and probate matters. His expertise was notably demonstrated in 2025 when he acted for Modalku Ventures Sdn. Bhd., Southeast Asia's premier SME digital financing platform, successfully securing judgments totaling RM2.01 million against 32 entities through a strategic large-scale peer-to-peer financing recovery exercise.

General Litigation

Tortious Claim
Advocate & Solicitor of the High Court of Malaya

Member of the Kuala Lumpur Bar Civil Practice and Court Liaison Committee (2024/2025)

Notable cases

Mujahid took on this matter on a pro bono basis, representing a retiree of a state-owned university in a novel suit challenging the unlawful annulment of his retirement benefit scheme. The case raised intricate questions around contractual prerequisites for variation of employment terms. While the suit was dismissed at the High Court, the matter proceeds to the Court of Appeal where the fight for the retiree's rights continues

Mohammad Sulaiman v. Universiti Selangor (UNISEL) Sdn Bhd [2025] CLJU 275

Mujahid represented the wife and children of a litigant in a landmark civil suit involving a declaration of religious status and the rectification of birth certificate records by the National Registration Department. Navigating a matter of profound personal and constitutional significance, Mujahid successfully secured the dismissal of all declaratory reliefs sought.

Muralee YS Menon v. Ketua Pengarah Jabatan Pendaftaran Negara; Farhana Farhan Menon & Ors (Interveners) [2025] CLJU 135

Qayyim

Corporate Advisor . Negotiator .

Qayyim graduated from Universiti Teknologi MARA (UiTM) in 2023 and completed his pupillage at Messrs Azmi & Associates, one of Malaysia's most established corporate law firms. He was admitted as an Advocate and Solicitor of the High Court of Malaya in 2024. His passion for corporate law was ignited early, through internships at several prominent law firms in Kuala Lumpur where he first encountered the fast-moving world of corporate transactions. During his pupillage, Qayyim deepened that foundation across private equity investments, commercial projects, licensing requirements and due diligence exercises. Ambitious and driven, Qayyim brings that same hunger to YAZ, where he continues to carve his path in corporate and commercial law, private shares and corporate finance.

Corporate & Commercial

Private Shares

Corporate Finance
Advocate & Solicitor of the High Court Malaya

Notable cases

Qayyim acted for Bank Kerjasama Rakyat Malaysia Berhad in a high-value financing facility of up to RM250 million extended to Koperasi Polis Diraja Malaysia Berhad. The transaction involved structuring complex security arrangements including multiple Deed of Assignments, Debentures and Memorandum of Deposits, reflecting the level of precision and technical sophistication required in large-scale corporate financing work.

Majlis Amanah Rakyat v. Pernec Integrated Network Systems Sdn Bhd [2025] MLJU 724
Qayyim acted for Koperasi Co-opbank Pertama Malaysia Berhad in a Corporate Term Financing Facility amounting to RM26 million structured under the Shariah principle of Murabahah Commodity. The transaction involved navigating intricate security arrangements including a charge over Malay Reserve Land, requiring a firm command of both Islamic financing principles and land law.

Koperasi Co-opbank Pertama Malaysia Berhad YAZ.2.2.1175.2025

Melissa

Litigator . Apprentice .

An alumna of the University of Liverpool, Melisa Ho Mun Wai graduated with an LL.B (Hons) in 2021 before completing the Certificate in Legal Practice (CLP) in 2022. She underwent her pupillage at the Firm under the guidance of Yusfarizal Yussoff, where she gained significant exposure to high-level litigation, particularly in complex tortious and contractual claims involving public institutions and private entities. Following her admission as an Advocate and Solicitor of the High Court of Malaya in August 2025, Melisa joined the Firm’s dispute resolution department. She currently manages a diverse portfolio of litigation matters, including contractual disputes, tortious claims, and public interest litigation, while also serving as an active member of the Kuala Lumpur Bar Young Lawyers Committee (2024/2025).

General Litigation

Contractual Disputes

Tortious Claims

Public Interest Litigation
Advocate & Solicitor of the High Court Malaya

Professional Membership at Kuala Lumpur Bar Young Lawyers Committee

Notable cases

Melissa was part of the team that successfully represented Besut District Council in a nationally publicised case involving the shooting of a stray dog named "Kopi", an incident that went viral and sparked significant public debate on animal welfare in Malaysia.

The plaintiffs sought declaratory reliefs challenging the Council's actions under the Animal Welfare Act 2015, raising novel questions on locus standi, civil court jurisdiction over penal provisions, and the validity of local authority by-laws. The High Court dismissed the originating summons in its entirety, upholding the Council's position across all five issues and affirming that the relevant by-laws were validly enacted and not ultra vires the AWA 2015.
Kartini Farah Abd Rahim & Ors v. Besut District Council & Anor [2026] MLRHU 808 | TA-22NCvC-233-12/2024